Safety Training Systems, Inc.
Safety Training Systems, Inc. appealed the deemed denial of its claim for an equitable adjustment of $1,550,603.87 due to increased costs under a contract to supply an aircraft trainer. The Board found that while STS was entitled to some compensation, the majority of the claim was denied.
Material Facts
- The contract was awarded to STS for the delivery and installation of an aircraft training platform in Yajooz, Jordan.
- The contract was a firm fixed-price contract with a total price of $2,274,889.57 after modifications.
- STS incurred unforeseen shipping costs that exceeded its original bid of $313,774.
- The shipping delays resulted in a total of 72 days of excusable delay under the contract.
- The government provided laborers who were unskilled and equipment that was often faulty.
Parties
- Appellant
- Safety Training Systems, Inc.
- Respondent Agency
- U.S. Army Engineer District, Middle East
- Contract Number
- W912ER-06-C-0018
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Xerox CorporationNo. 63436, 63437November 22, 2023
- Northrop Grumman Systems Corporation Space Systems, Inc.No. 63512November 22, 2023
- Pigott Asphalt and Sitework, LLCNo. 63731November 21, 2023
- Delta Mechanical Contractors, LLCNo. 63593November 21, 2023
- Kondazi EnterpriseNo. 63628October 2, 2023
- Fluor-AMEC II, LLCNo. 63554September 28, 2023
Same Year
- Fluor Enterprises, Inc. and Fluor CorporationNo. 59367, 59697December 24, 2014
- The Boeing CompanyNo. 59216December 24, 2014
- Government Services Corp.No. 59654December 23, 2014
- Raytheon Missile SystemsNo. 59432December 23, 2014
- CAE USA, Inc.No. 58957December 23, 2014
- Metal Storm, Inc.No. 58901December 23, 2014
Same Issue
- Procal Electric, Inc.No. 63580-ADROctober 2, 2026
- Kearfott CorporationNo. 64328October 1, 2026
- Relyant Global, LLCNo. 64606October 1, 2026
- Relyant Global, LLCNo. 64651October 1, 2026
- Korte Construction CompanyNo. 63539, 63540September 30, 2026
- GiaMed Alliance JV, LLCNo. 64484September 29, 2026