Areyana Group of Construction Company

Material Facts

• The government entered into a fixed-price contract with AGCC in a total amount of $4,754,401.51.
• The project involved the design and construction of facilities to support the Afghanistan National Police program.
• AGCC requested a 221-day, no-cost time extension due to supply issues and shipping delays.
• The contracting officer issued a cure notice to AGCC citing failures in performance.
• AGCC submitted several requests for time extensions and claims, none of which included the required certification.
• The contracting officer found AGCC's request for a time extension to be baseless and without merit.

Parties

Appellant

Areyana Group of Construction Company

Respondent Agency

U.S. Army Engineer District

Contract Number

W5J9LE-12-C-0044