Nova Group, Inc.
Nova Group, Inc. appealed a decision regarding differing site conditions and delays related to a contract with the U.S. Navy for the construction of a supply pier. The Board denied the appeal, finding no merit in the claims.
Material Facts
- The contract was awarded to Nova Group, Inc. by the U.S. Navy for the design and construction of a supply pier.
- The original completion date was extended due to delays.
- Nova claimed differing site conditions based on geotechnical reports that indicated subsurface conditions.
- The Navy conducted additional borings after Nova reported settlement issues with the trestle.
- The contracting officer awarded Nova $2,169,492 in two unilateral modifications for differing site conditions.
Parties
- Appellant
- Nova Group, Inc.
- Respondent Agency
- U.S. Navy
- Contract Number
- N68711-02-C-2004
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Macro-Z-TechnologyNo. 56711January 29, 2013
- ThinkQ, Inc.No. 57732January 24, 2013
- TMS Envirocon, Inc.December 12, 2012
- Hanley Industries, Inc.No. 56584November 29, 2012
- AM General, LLCNo. 57662September 17, 2012
- TMS Envirocon, Inc.No. 57286June 19, 2012
Same Year
- C.E.M.E.S. S.p.A.No. 56253, 57355December 29, 2010
- Shaw Environmental, Inc.No. 57237December 16, 2010
- Thorington Electrical and Construction CompanyNo. 56997December 13, 2010
- Phoenix Management, Inc.No. 57234December 13, 2010
- Parsons Global Services, Inc.No. 56731December 3, 2010
- Kelly-Ryan, Inc.No. 57168November 29, 2010
Same Issue
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026
- PDO Ahusaka Joint Venture LLCNo. 64490July 23, 2026
- Meltech Corporation, Inc.No. 61762, 61764January 16, 2026
- Healtheon, Inc.No. 63145July 24, 2025
- Skanska USA Civil Southeast, Inc.No. 61220, 61347April 3, 2025
- David Boland, Inc.No. 60498March 6, 2025