TTF, L.L.C.
TTF, L.L.C. appealed the contracting officer's denial of its claim for government-caused delays under Contract No. FA8103-07-C-0219. The Board denied the government's motion for summary judgment, allowing the appeal to proceed.
Material Facts
- The contract was awarded to TTF for two aircraft landing gear doors to be delivered by 31 December 2008 for a fixed price of $134,182.40.
- TTF's production was on hold pending a response from the contracting officer regarding aluminum alloy specifications.
- DCMA issued several Corrective Action Reports alleging discrepancies in TTF's heat treating process.
- TTF requested contract modifications that extended the delivery date to 4 November 2011.
- TTF claimed that delays were caused by the government's failure to provide necessary specifications and support.
- TTF's final corrective action reply indicated that contamination concerns were addressed and corrective measures were implemented.
- The contracting officer denied TTF's claim in its entirety on 7 November 2012.
Parties
- Appellant
- TTF, L.L.C.
- Contract Number
- FA8103-07-C-0219
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- PAW & Associates, LLCNo. 58534August 20, 2015
- DayDanyon CorporationNo. 57681August 17, 2015
- DynPort Vaccine Company LLCNo. 59298August 12, 2015
- Tri-County Contractors, Inc.No. 58167June 16, 2015
- Linc Government Services, LLCNo. 58565June 16, 2015
- SUFI Network Services, Inc.No. 55306May 20, 2015
Same Year
- WorleyParsons International, Inc.No. 57930December 20, 2013
- Bruce E. ZoellerNo. 56578December 17, 2013
- New Iraq Ahd CompanyNo. 58800December 17, 2013
- Linc Government Services, LLCNo. 58561, 58562, 58563, 58565, 58566, 58567December 5, 2013
- Fluor CorporationNo. 57852December 5, 2013
- The Boeing CompanyNo. 58587December 3, 2013
Same Issue
- Procal Electric, Inc.No. 63580-ADROctober 2, 2026
- Kearfott CorporationNo. 64328October 1, 2026
- Relyant Global, LLCNo. 64606October 1, 2026
- Relyant Global, LLCNo. 64651October 1, 2026
- Korte Construction CompanyNo. 63539, 63540September 30, 2026
- GiaMed Alliance JV, LLCNo. 64484September 29, 2026