TTF, L.L.C.
TTF, L.L.C. appealed the denial of its claim for government delay costs under Contract No. FA8103-07-C-0219 following a default termination. The Board denied the appeal, finding TTF did not prove the specifications were impossible to perform.
Material Facts
- The contract was awarded to TTF for two aircraft landing gear doors with a delivery date of 31 December 2008.
- TTF did not deliver the doors by the agreed dates, leading to a cumulative extension of 1,038 days.
- TTF's claims included allegations of improper inspection actions by DCMA and delays caused by specification interpretations.
- The TCO denied TTF's claims, leading to the appeal.
Parties
- Appellant
- TTF, L.L.C.
- Respondent Agency
- Department of the Air Force
- Contracting Agency
- Oklahoma City Air Logistics Center
- Contract Number
- FA8103-07-C-0219
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- PAW & Associates, LLCNo. 58534August 20, 2015
- DayDanyon CorporationNo. 57681August 17, 2015
- DynPort Vaccine Company LLCNo. 59298August 12, 2015
- Tri-County Contractors, Inc.No. 58167June 16, 2015
- Linc Government Services, LLCNo. 58565June 16, 2015
- SUFI Network Services, Inc.No. 55306May 20, 2015
Same Year
- Fluor Enterprises, Inc. and Fluor CorporationNo. 59367, 59697December 24, 2014
- The Boeing CompanyNo. 59216December 24, 2014
- Government Services Corp.No. 59654December 23, 2014
- Raytheon Missile SystemsNo. 59432December 23, 2014
- CAE USA, Inc.No. 58957December 23, 2014
- Metal Storm, Inc.No. 58901December 23, 2014
Same Issue
- Bodell Construction CompanyNo. 63517-ADR, 63850-ADROctober 2, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- WSP USA Solutions Inc.No. 62674September 1, 2026
- Mvation Worldwide Inc.No. 64633August 18, 2026
- U.S. Aeroteam, Inc.No. 61972, 61973August 6, 2026