Hedgecock Electric, Inc.
Hedgecock Electric, Inc. appealed a decision regarding compensable delays and liquidated damages under a Navy construction contract. The Board found in favor of Hedgecock for certain delays but upheld the government's assessment of liquidated damages.
Material Facts
- The Navy awarded a firm, fixed-price contract to Hedgecock Electric, Inc. for construction and repair work.
- HECI sought an extension of the contract performance period and compensatory damages due to alleged government-caused delays.
- The contract included provisions for liquidated damages for delays.
- The government assessed liquidated damages against HECI for failing to complete the work by the contractual completion date.
- The Board found that HECI experienced a total of 43 days of compensable government-caused delay.
Parties
- Appellant
- Hedgecock Electric, Inc.
- Respondent Agency
- Navy
- Contract Number
- N69272-06-C-0003
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Kelly-Ryan, Inc.No. 57168December 5, 2017
- Optimum Services, Inc.No. 58755, 59952July 20, 2017
- Raytheon Company and Raytheon Missile SystemsNo. 61191, 61192, 61193June 6, 2017
- Raytheon CompanyNo. 58849May 2, 2017
- Swinerton Builders NorthwestNo. 57329April 24, 2017
- General Atomics Aeronautical Systems, Inc.No. 60002, 60003March 24, 2017
Same Year
- Gray Personnel, Inc.No. 54652, 55833December 31, 2012
- ECC, InternationalNo. 55781December 28, 2012
- DODS, Inc.December 18, 2012
- Raytheon CompanyNo. 57576, 57679December 17, 2012
- TMS Envirocon, Inc.December 12, 2012
- The Public Warehousing CompanyDecember 3, 2012
Same Issue
- Bodell Construction CompanyNo. 63517-ADR, 63850-ADROctober 2, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- WSP USA Solutions Inc.No. 62674September 1, 2026
- Mvation Worldwide Inc.No. 64633August 18, 2026
- U.S. Aeroteam, Inc.No. 61972, 61973August 6, 2026