Dyno Group, Inc.
Dyno Group, Inc. appealed the denial of its claim challenging the assessment of liquidated damages for late completion of a contract with the United States Army Corps of Engineers. The Board denied the appeal.
Material Facts
- Dyno Group, Inc. was awarded Contract No. W912P4-11-C-0016 on 22 September 2011.
- The contract required completion of the work within 180 days from the Notice to Proceed, with additional time for options.
- Dyno received the Notice to Proceed on 3 October 2011, establishing a completion date of 31 March 2012 for the base work.
- The contracting officer assessed liquidated damages of $39,600 for 88 days of delay from 24 September 2012 until 21 December 2012.
- Dyno's claims for extensions were based on various reasons, including unforeseen site conditions and delays from Hurricane Sandy.
Parties
- Appellant
- Dyno Group, Inc.
- Respondent Agency
- U.S. Army Engineer District, Buffalo
- Contracting Agency
- United States Army Corps of Engineers
- Contract Number
- W912P4-11-C-0016
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- HECO Pacific Manufacturing, Inc.No. 63217, 64512September 1, 2026
- Erik Robinson d/b/a The Artwork FactoryNo. 63727, 63809August 19, 2026
- ACC Construction Co., Inc.No. 63528, 64067July 16, 2026
- Gibraltar-Caddell, a Joint VentureNo. 64379July 13, 2026
- Akima Range Readiness Operations, LLCNo. 64012-ADRJune 4, 2026
- Envistacom, LLCNo. 63796May 13, 2026
Same Year
- Fluor Enterprises, Inc. and Fluor CorporationNo. 59367, 59697December 24, 2014
- The Boeing CompanyNo. 59216December 24, 2014
- Government Services Corp.No. 59654December 23, 2014
- Raytheon Missile SystemsNo. 59432December 23, 2014
- CAE USA, Inc.No. 58957December 23, 2014
- Metal Storm, Inc.No. 58901December 23, 2014
Same Issue
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026
- J.A.M. Construction Services, Inc.No. 63378, 64226, 64439July 28, 2026
- ACC Construction Co., Inc.No. 63528, 64067July 16, 2026
- Healtheon, Inc.No. 63145July 24, 2025
- Gideon Contracting, LLCNo. 63561May 12, 2025
- ECC International Constructors, LLCNo. 59586April 18, 2025