ECC International Constructors, LLC

Material Facts

• The contract was awarded on September 29, 2010, for $29,186,338 to design and construct a military compound in Afghanistan.
• ECCI was to complete the work within 548 days of the notice to proceed, with a revised completion date of March 13, 2013.
• The government approved ECCI's 95% design on August 23, 2011, but disapproved the 100% design on December 16, 2011, requiring multiple resubmissions.
• The government finally approved the 100% communications design on March 14, 2013.
• ECCI substantially completed the project on April 19, 2014, 402 days after the revised completion date.
• ECCI claimed $9,035,587 and the return of 400 days of withheld liquidated damages due to alleged government-caused delays.

Parties

Appellant

ECC International Constructors, LLC

Respondent Agency

U.S. Army Engineer District, Middle East

Contract Number

W912ER-10-C-0054