Lebolo-Watts Constructors 01 JV, LLC

Material Facts

• The contract was awarded on August 8, 2011, for a total amount of $18,392,000.
• The contractor received the Notice to Proceed on September 6, 2011, with a contract duration of 600 days.
• The contractor claimed it was made to perform beyond contract requirements and that the government caused delays in providing permanent power.
• The contractor's claims included costs for providing replacement circuit breakers and delays associated with permanent power.
• The Board found that the contractor was responsible for delays due to its own performance issues.

Parties

Appellant

Lebolo-Watts Constructors 01 JV, LLC

Respondent Agency

U.S. Army Corps of Engineers

Contract Number

W912DR-11-C-0033