Relyant, LLC
Relyant, LLC appealed a decision regarding the acceptance of relocatable buildings under a government contract, which resulted in a partial award for damages due to government delays.
Material Facts
- The contract was a multiple award, indefinite-delivery/indefinite-quantity (IDIQ) contract for the manufacture, delivery, and installation of relocatable buildings in Afghanistan.
- Relyant proposed a different configuration for the buildings than what was specified in the contract's statement of work (SOW).
- The government accepted some of Relyant's buildings at one site but rejected them at another site due to non-compliance with the SOW.
- Relyant's request to use a sandwich panel instead of drywall was not approved by the Contracting Officer.
- The government delayed its response to Relyant's request for several months, which caused Relyant to incur additional costs.
Parties
- Appellant
- Relyant, LLC
- Respondent Agency
- Department of the Army
- Contract Number
- W91B4N-08-D-0011
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- KBR Services, LLCNo. 63870, 63956August 24, 2026
- AeroKool Aviation CorporationNo. 64377August 24, 2026
- Kropp Holdings, Inc.No. 64523August 24, 2026
- BFBC, LLCNo. 64509August 18, 2026
- Mvation Worldwide Inc.No. 64633August 18, 2026
- Perma-Fix Environmental Services, Inc.No. 64438July 30, 2026
Same Year
- AT&T Corp.No. 61868December 21, 2018
- Gilbane Federal Joint VentureNo. 61590December 21, 2018
- WIT Associates, Inc.No. 61547December 19, 2018
- Avis Industries, Inc.No. 61609December 19, 2018
- Tetra Tech Tesoro, Inc.No. 61209, 61210, 61211, 61212 61213, 61214December 19, 2018
- J.F. Brennan Co., Inc.No. 60737December 19, 2018
Same Issue
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- Vigor Marine, LLCNo. 63405September 24, 2026
- US Military CorpNo. 64321September 24, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026