MULE Engineering, Inc.
MULE Engineering, Inc. appealed multiple claims against the Army regarding delays and additional costs incurred during a construction contract. The Board denied all claims, finding concurrent delays and lack of evidence supporting MULE's assertions.
Material Facts
- The Army awarded a firm-fixed-price contract to MULE Engineering, Inc. for construction work.
- MULE experienced delays and incurred additional costs due to alleged constructive changes and defective specifications.
- MULE's CEO testified that the company was unable to secure a subcontractor for critical work until several months after the contract was awarded.
- The Army contended that any delays were concurrent with delays caused by MULE.
- The Board found that MULE did not provide sufficient evidence to support its claims.
Parties
- Appellant
- MULE Engineering, Inc.
- Respondent Agency
- Department of the Army
- Contract Number
- W9124M-14-C-0014
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Sauer IncorporatedNo. 62302, 62303December 18, 2024
- Platinum Services, Inc.No. 62199, 62200August 1, 2024
- Modus Operandi, Inc.No. 62639August 30, 2023
- The Boeing CompanyNo. 63360-ADRApril 6, 2023
- Advanced Technologies Group, Inc.No. 59986, 61092November 18, 2020
- Al Arrab Contracting Co., Ltd.No. 58493, 58877November 4, 2020
Same Year
- Columbia State Bank f/k/a Castle-Rose, Inc.No. 59531December 28, 2017
- Fluor Federal Solutions, LLCNo. 61431-983December 28, 2017
- Goodwill Services, Inc.No. 61439December 27, 2017
- Suffolk Construction Company, Inc.No. 60990December 27, 2017
- Parsons Government Services, Inc.No. 60218December 21, 2017
- Parsons Government Services, Inc.No. 60221December 21, 2017
Same Issue
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- Vigor Marine, LLCNo. 63405September 24, 2026
- US Military CorpNo. 64321September 24, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026