Sand Point Services, LLC
Sand Point Services, LLC appealed decisions regarding extra costs and delays from a contract with NASA for repairs at the Wallops Flight Facility, alleging differing site conditions and constructive changes. The Board denied NASA's motions to dismiss and for summary judgment.
Material Facts
- NASA entered into Contract No. NNG14WA50C with SPS to repair the Wallops Flight Facility's aircraft parking apron.
- SPS alleged it incurred extra costs and delays due to unsuitable soil, a differing site condition.
- NASA issued a final decision stating that SPS released its differing site condition claim in a modification.
- SPS signed Modification No. 000002 under threat of termination for default.
- SPS admitted that the concrete texture and mooring eyes did not meet specifications but claimed these were minor issues.
Parties
- Appellant
- Sand Point Services, LLC
- Respondent Agency
- NASA
- Contracting Agency
- NASA
- Contract Number
- NNG14WA50C
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Procal Electric, Inc.No. 63580-ADROctober 2, 2026
- VESEQU LLCNo. 64468August 21, 2026
- PDO Ahuska Joint Venture LLCNo. 64164July 13, 2026
- First Street Contractors, LLCNo. 64028June 10, 2026
- VESEQU LLCNo. 64468May 21, 2026
- First Street Contractors, LLCNo. 64028February 20, 2026
Same Year
- Club Car, Inc.No. 61710December 30, 2019
- Universal Service Provider, LLCNo. 62021December 23, 2019
- Technica CorporationNo. 62160December 20, 2019
- AXXON International, LLCNo. 61224, 61268, 61625December 20, 2019
- Naseem Al-Oula CompanyNo. 61321, 61322, 61323, 61324, 61325, 61326December 20, 2019
- Ford Lumber & Building Supply, Inc.No. 61618December 18, 2019
Same Issue
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026
- PDO Ahusaka Joint Venture LLCNo. 64490July 23, 2026
- Meltech Corporation, Inc.No. 61762, 61764January 16, 2026
- Healtheon, Inc.No. 63145July 24, 2025
- Skanska USA Civil Southeast, Inc.No. 61220, 61347April 3, 2025
- David Boland, Inc.No. 60498March 6, 2025