MVP Network Consulting, LLC

Material Facts

• The Department of the Army awarded Contract No. W911S2-21-P-1765 to MVP for the purchase and delivery of computer monitors and printers on September 21, 2021.
• The contract included FAR 52.212-4 and FAR 52.233-1.
• The Army requested a status update from MVP on December 21, 2021.
• The Army informed MVP on February 10, 2022, that it had received the monitors and requested an estimated delivery date for the printers.
• The Army notified MVP on March 9, 2022, that it needed supporting documentation regarding the delay or a partial termination for cause would be initiated.
• The contracting officer issued a final decision partially terminating the contract for cause on July 27, 2022.
• MVP acknowledged receipt of the termination notice on August 24, 2022.
• MVP's notice of appeal was submitted on November 25, 2022.

Parties

Appellant

MVP Network Consulting, LLC

Respondent Agency

Department of the Army

Contract Number

W911S2-21-P-1765