TTF, L.L.C.
TTF, L.L.C. appealed the termination of its contract by the Defense Logistics Agency, claiming entitlement to price adjustments for delays. The Board denied the appeal, ruling that the contract had lapsed due to nonperformance.
Material Facts
- TTF submitted a quote for aircraft fuselage fairings under a HUBZone set-aside contract.
- The Defense Logistics Agency issued a unilateral Purchase Order to TTF for a total price of $88,896.14.
- TTF subcontracted the manufacturing of the fairings to a non-HUBZone business, Eltee Tool & Die Co.
- TTF failed to send the first article test report to the correct address, causing delays in evaluation.
- TTF did not deliver the production quantity of fairings by the required date, leading to a show cause notice.
- The Contracting Officer canceled the remaining quantity of the Purchase Order due to TTF's failure to deliver.
Parties
- Appellant
- TTF, L.L.C.
- Respondent Agency
- Defense Logistics Agency
- Contracting Agency
- Defense Supply Center Richmond
- Contract Number
- SPM4A7-09-M-2635
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Sauer IncorporatedNo. 62302, 62303December 18, 2024
- Platinum Services, Inc.No. 62199, 62200August 1, 2024
- Modus Operandi, Inc.No. 62639August 30, 2023
- The Boeing CompanyNo. 63360-ADRApril 6, 2023
- Advanced Technologies Group, Inc.No. 59986, 61092November 18, 2020
- Al Arrab Contracting Co., Ltd.No. 58493, 58877November 4, 2020
Same Year
- WorleyParsons International, Inc.No. 57930December 20, 2013
- TTF, L.L.C.No. 58452December 19, 2013
- Bruce E. ZoellerNo. 56578December 17, 2013
- New Iraq Ahd CompanyNo. 58800December 17, 2013
- Linc Government Services, LLCNo. 58561, 58562, 58563, 58565, 58566, 58567December 5, 2013
- Fluor CorporationNo. 57852December 5, 2013
Same Issue
- Bodell Construction CompanyNo. 63517-ADR, 63850-ADROctober 2, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- WSP USA Solutions Inc.No. 62674September 1, 2026
- Mvation Worldwide Inc.No. 64633August 18, 2026
- U.S. Aeroteam, Inc.No. 61972, 61973August 6, 2026