Alderman Building Company, Inc.
Alderman Building Company, Inc. appealed a decision regarding unabsorbed home office overhead costs due to delays in a renovation contract with the Navy. The Board partially sustained the appeal, awarding a net amount to Alderman.
Material Facts
- The Navy awarded a Task Order for renovations to Alderman on March 27, 2009.
- The contract completion date was initially set for March 22, 2010.
- Alderman entered into a subcontract with Big John’s Electric Co., Inc. on April 8, 2009.
- The Navy caused delays totaling 263 days, pushing the start work date into February 2010.
- Alderman began contract performance on February 19, 2010.
- Alderman submitted a claim for $20,518 on August 18, 2011, which was denied by the contracting officer on January 19, 2012.
- The appeal was based on the expert opinion of Dr. Roger K. Seals regarding unabsorbed overhead.
Parties
- Appellant
- Alderman Building Company, Inc.
- Respondent Agency
- Navy
- Contract Number
- N40085-09-D-5321
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Naseem Al-Oula CompanyNo. 61321, 61322, 61323, 61324, 61325, 61326December 20, 2019
- Sauer IncorporatedNo. 61790December 18, 2019
- Arab Shah Construction CompanyNo. 61565November 4, 2019
- PIKA-Pirnie JV, LLCNo. 61597November 4, 2019
- Diversified Maintenance Systems, Inc.No. 61535July 22, 2019
- Quimba Software, Inc.No. 59197May 13, 2019
Same Year
- Sweet Star Logistic ServiceNo. 62082December 29, 2020
- Nan, Inc.No. 61472, 61482, 61500, 61509, 61514, 61523, 61555, 61569, 61705, 61726, 61727, 61728, 61821, 61822, 61823, 61963December 18, 2020
- Asahi General Trading & Cont. Co. W.L.L.No. 62445December 18, 2020
- Kautaq Construction Services, LLCNo. 62462-ADRDecember 18, 2020
- MAC Electric Inc.No. 62503December 18, 2020
- Parsons Government Services, Inc.No. 62112December 17, 2020
Same Issue
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026
- DCS CorporationNo. 64648September 22, 2026
- VAE, Inc.No. 64437, 64464, 64465September 9, 2026
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026