Highland Al Hujaz Co., Ltd.
Highland Al Hujaz Co., Ltd. appealed the U.S. Army Corps of Engineers' termination of its contract for default, arguing that the termination was improper due to various delays and financial issues. The Board upheld the termination, finding that Highland anticipatorily repudiated its obligation to provide temporary power.
Material Facts
- The contract was for the design and construction of an Afghan National Army installation.
- Highland was required to provide temporary power until permanent power was established.
- Highland failed to provide temporary power, leading to the government's termination of the contract for default.
- The Corps issued a cure notice due to Highland's failure to complete several facilities by the deadline.
Parties
- Appellant
- Highland Al Hujaz Co., Ltd.
- Respondent Agency
- U.S. Army Corps of Engineers
- Contract Number
- W917PM-09-C-0049
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Sierra Nevada CorporationNo. 63649February 24, 2026
- Sierra Nevada CorporationNo. 63933, 63934February 24, 2026
- Synergetic Technologies Group, Inc.No. 64361January 29, 2026
- Repeat Consultants International, LLCNo. 64188, 64189December 8, 2025
- Novielli Boat Builders Inc.No. 64281December 5, 2025
- United Capital Investments GroupNo. 64163December 2, 2025
Same Year
- Sparton DeLeon Springs, LLCNo. 60416December 28, 2016
- Kellogg Brown & Root Services, Inc.No. 59873, 60885December 21, 2016
- Lockheed Martin Integrated Systems, Inc.No. 59508, 59509December 20, 2016
- CDM Constructors, Inc.No. 59524December 20, 2016
- Astro Systems, Inc.No. 60769, 60781December 20, 2016
- First Division Design, LLCNo. 60884-975December 15, 2016
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- US Military CorpNo. 64321September 24, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Visionary Construction, Inc. dba Visionary ServicesNo. 64426August 20, 2026
- Peritia LLCNo. 64495, 64586August 20, 2026
- J.A.M. Construction Services, Inc.No. 63378, 64226, 64439July 28, 2026