Classic Site Solutions, Inc.
Classic Site Solutions, Inc. appealed the denial of its soil treatment claim related to delays in the issuance of a Notice to Proceed under Contract No. W912DR-l l-C-0022. The Board granted the government's motion for summary judgment in part and denied the appellant's motion.
Material Facts
- The contract involved construction of a test track for military vehicles at Aberdeen Proving Ground, Maryland.
- The U.S. Army Corps of Engineers issued Request for Proposals No. W912DR-l l-R-0021 for the project on 2 February 2011.
- The appellant submitted its proposal on 8 March 2011, indicating a total estimated bid amount of $13,368,055.67.
- The contract was awarded to Classic Site Solutions, Inc. on 31 May 2011, with the NTP issued on 21 June 2011.
- Classic Site Solutions, Inc. claimed $510,795.45 for damages caused by the late NTP.
Parties
- Appellant
- Classic Site Solutions, Inc.
- Respondent Agency
- U.S. Army Corps of Engineers
- Contract Number
- W912DR-l l-C-0022
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Metal Trades, Inc.No. 62966November 2, 2021
- Powertronic Systems Florida, Inc.No. 62174October 19, 2021
- Huffman Construction, LLCNo. 62591, 62783August 5, 2021
- U.S. Pan American Solutions, LLCNo. 62629August 5, 2021
- URS Federal Support Services, Inc.No. 59998-QUANAugust 3, 2021
- G&S Carpet Mills, Inc.No. 62799June 25, 2021
Same Year
- Fluor Enterprises, Inc. and Fluor CorporationNo. 59367, 59697December 24, 2014
- The Boeing CompanyNo. 59216December 24, 2014
- Government Services Corp.No. 59654December 23, 2014
- Raytheon Missile SystemsNo. 59432December 23, 2014
- CAE USA, Inc.No. 58957December 23, 2014
- Metal Storm, Inc.No. 58901December 23, 2014
Same Issue
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- Vigor Marine, LLCNo. 63405September 24, 2026
- US Military CorpNo. 64321September 24, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026