Terraseis Trading Limited

Material Facts

• Terraseis contracted with the government for seismic data collection and processing in Afghanistan.
• The government terminated the contract for cause due to Terraseis's failure to meet the delivery date.
• Terraseis submitted a certified claim for delay costs, which the contracting officer denied.
• The contract required the government to deliver equipment to Terraseis, but the delivery was delayed.
• Terraseis experienced concurrent delays due to security issues and attacks on its crew.

Parties

Appellant

Terraseis Trading Limited

Respondent Agency

Department of Defense

Contract Number

W91B4N-12-C-5045