TranLogistics LLC
TranLogistics LLC appealed for reconsideration of a prior decision regarding delay damages under Contract No. M27100-17-P-6012, resulting in a partial award of the claimed amount.
Material Facts
- TranLogistics submitted invoice 1368 as an 'REA' to recover delay damages.
- The invoice requests payment for 6 days of delay for carriers totaling $13,853.00.
- The decision did not award payment of this invoice because TranLogistics had not otherwise segregated the time and cost of the delay.
- TranLogistics provided direct proof that September 28-October 4 are the days of compensable delay.
- The subcontractor's invoice charges $12,353 for the time between September 28 and October 4, 2017, due to delay of government documents and unforeseen situations.
Parties
- Appellant
- TranLogistics LLC
- Contract Number
- M27100-17-P-6012
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Hejran Hejrat Co. LTDNo. 61234December 2, 2020
- APTIM Federal Services, LLCNo. 62052, 62133September 18, 2020
- Lavender Co.No. 62163July 29, 2020
- Meltech/W.M. Schlosser Construction, LLC, Joint VentureNo. 61752July 2, 2020
- John C. Grimberg Co., Inc.No. 61243, 61244, 61245,61425, 61426April 22, 2020
- AISG, Inc.No. 58696, 59151March 30, 2020
Same Year
- Club Car, Inc.No. 61710December 30, 2019
- Universal Service Provider, LLCNo. 62021December 23, 2019
- Technica CorporationNo. 62160December 20, 2019
- AXXON International, LLCNo. 61224, 61268, 61625December 20, 2019
- Naseem Al-Oula CompanyNo. 61321, 61322, 61323, 61324, 61325, 61326December 20, 2019
- Ford Lumber & Building Supply, Inc.No. 61618December 18, 2019
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026
- Hensel Phelps Construction CompanyNo. 64327September 14, 2026
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Marine Hydraulics International, LLCNo. 63429, 63511August 6, 2026