PricingGAO ProtestASBCACMMCMCPFAQResources
63153

Lacy Mechanical, Inc.

June 4, 2024Judge Eyester
DismissedContract Changes / Constructive ChangesQuantum / DamagesAccord & Satisfaction / Release / Waiver

Lacy Mechanical, Inc. appealed a decision regarding a breach of contract claim against the U.S. Army Corps of Engineers, which was dismissed by the Board on summary judgment.

Material Facts

  • Lacy Mechanical, Inc. entered into a contract with the U.S. Army Corps of Engineers for work at the Ice Harbor dam.
  • The Corps delivered cables to Lacy, which required additional spelter work before installation.
  • Lacy claimed delays due to the late delivery of cables and COVID-19 impacts.
  • The Corps issued a bilateral modification that included a release of future claims related to the modification.

Parties

Appellant
Lacy Mechanical, Inc.
Respondent Agency
U.S. Army Corps of Engineers
Contract Number
W912EF-16-D-0021
Open Official Decision PDF (asbca.mil)AI-analyzed, grounded in the decision text. Verify against the official PDF before relying on it.

Full Legal Analysis

Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.

Holding & Legal Reasoning

The Board's holding, background, and procedural posture for this decision.

View plans and pricing

Issues Presented

Every issue the Board decided, with its determination, reasoning, and supporting authority.

View plans and pricing

Quantum & Recovery

The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.

View plans and pricing

Verified Authorities & Citations

Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.

View plans and pricing

Practitioner Takeaways

Practical guidance for contractors and counsel, distilled from the Board's ruling.

View plans and pricing

Similar Cases

Related decisions surfaced by semantic search across the full analyzed corpus.

View plans and pricing

Citation Graph

An interactive graph of this case's cited authorities, judge, agency, and related decisions.

View plans and pricing

Related Decisions

Same Judge

Same Year

Same Issue

Newsletter

New decisions every Monday

GovConDash Weekly lists the decisions GAO, the boards, the courts and SBA OHA released that week, alongside the FAR Overhaul deviations and proposed rules that reach every contractor. Free.

Free, weekly, and one click to unsubscribe. We send a confirmation email first. See our Privacy Policy.