States Roofing Corporation
States Roofing Corporation appealed four decisions related to Contract No. N62470-97-C-8319 concerning delays, acceleration, and disruption claims. The Board dismissed one appeal, denied another, and partially sustained two others, awarding a total of $161,479.
Material Facts
- The contract was awarded to States Roofing Corporation for roofing repairs at Naval Operating Base Norfolk.
- SRC experienced delays due to a defective submittal register and other issues.
- The Navy issued several unilateral modifications during the contract performance.
- SRC's claims included requests for time extensions and additional compensation for delays and disruptions.
Parties
- Appellant
- States Roofing Corporation
- Respondent Agency
- Navy
- Contract Number
- N62470-97-C-8319
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Macro-Z-TechnologyNo. 56711January 29, 2013
- ThinkQ, Inc.No. 57732January 24, 2013
- TMS Envirocon, Inc.December 12, 2012
- Hanley Industries, Inc.No. 56584November 29, 2012
- AM General, LLCNo. 57662September 17, 2012
- TMS Envirocon, Inc.No. 57286June 19, 2012
Same Year
- C.E.M.E.S. S.p.A.No. 56253, 57355December 29, 2010
- Shaw Environmental, Inc.No. 57237December 16, 2010
- Thorington Electrical and Construction CompanyNo. 56997December 13, 2010
- Phoenix Management, Inc.No. 57234December 13, 2010
- Parsons Global Services, Inc.No. 56731December 3, 2010
- Kelly-Ryan, Inc.No. 57168November 29, 2010
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026
- Hensel Phelps Construction CompanyNo. 64327September 14, 2026
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Marine Hydraulics International, LLCNo. 63429, 63511August 6, 2026