Lan-Cay, Inc.
Lan-Cay, Inc. appealed a termination for default by the government regarding a contract for Blank Firing Attachments, alleging improper audits and government-caused delays. The Board denied the appeal, finding the termination justified.
Material Facts
- The Army awarded Contract No. DAAE20-03-D-0170 to Lan-Cay, Inc. for the production of Blank Firing Attachments.
- The contract was an indefinite-delivery, indefinite-quantity (IDIQ) contract.
- No production quantities had been delivered under the contract by the time of termination on 29 March 2007.
- The contract incorporated numerous standard FAR clauses, including FAR 52.249-8, DEFAULT.
- The government issued a notice of termination due to Lan-Cay's failure to meet scheduled delivery dates and quality requirements.
Parties
- Appellant
- Lan-Cay, Inc.
- Respondent Agency
- Department of the Army
- Contract Number
- DAAE20-03-D-0170
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Kearfott CorporationNo. 64328October 1, 2026
- Relyant Global, LLCNo. 64606October 1, 2026
- Relyant Global, LLCNo. 64651October 1, 2026
- GiaMed Alliance JV, LLCNo. 64484September 29, 2026
- DCS CorporationNo. 64648September 22, 2026
- Wild Hare Haulers, LLCNo. 64596, 64597, 64598September 15, 2026
Same Year
- Gray Personnel, Inc.No. 54652, 55833December 31, 2012
- ECC, InternationalNo. 55781December 28, 2012
- DODS, Inc.December 18, 2012
- Raytheon CompanyNo. 57576, 57679December 17, 2012
- TMS Envirocon, Inc.December 12, 2012
- The Public Warehousing CompanyDecember 3, 2012
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- US Military CorpNo. 64321September 24, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Visionary Construction, Inc. dba Visionary ServicesNo. 64426August 20, 2026
- Peritia LLCNo. 64495, 64586August 20, 2026
- J.A.M. Construction Services, Inc.No. 63378, 64226, 64439July 28, 2026