SERDI, LLC
SERDI, LLC appealed a decision regarding payment for services under a firm-fixed-price contract with the Defense Intelligence Agency, claiming that the Agency's actions prevented it from fulfilling contract requirements. The Board denied the Agency's motion for summary judgment, finding disputed material facts.
Material Facts
- DIA awarded SERDI a firm-fixed-price, level of effort contract in the amount of $786,862.00.
- The contract required SERDI to provide 9,600 hours of support services.
- SERDI did not submit any invoices for the first six months of the base year.
- SERDI submitted invoices totaling $522,588.47 to close out the base year, which DIA rejected.
- SERDI alleged that DIA's actions, including delays in processing security clearances, prevented it from staffing the project.
Parties
- Appellant
- SERDI, LLC
- Respondent Agency
- Defense Intelligence Agency
- Contract Number
- HHM402-10-C-0140
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Advanced Constructors International, LLCNo. 58604, 58739, 58740, 58741October 8, 2015
- Capy Machine Shop, Inc.No. 59085October 8, 2015
- Capy Machine Shop, Inc.No. 59133October 8, 2015
- Areebel Engineering & LogisticsNo. 58648, 58649, 58650, 58651October 5, 2015
- Hashmat Khalil Rezai Road & Construction ComanyNo. 58868September 1, 2015
- Development & Evolution Construction Co.No. 59462September 1, 2015
Same Year
- WorleyParsons International, Inc.No. 57930December 20, 2013
- TTF, L.L.C.No. 58452December 19, 2013
- Bruce E. ZoellerNo. 56578December 17, 2013
- New Iraq Ahd CompanyNo. 58800December 17, 2013
- Linc Government Services, LLCNo. 58561, 58562, 58563, 58565, 58566, 58567December 5, 2013
- Fluor CorporationNo. 57852December 5, 2013
Same Issue
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- Vigor Marine, LLCNo. 63405September 24, 2026
- US Military CorpNo. 64321September 24, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026