DODS, Inc.
DODS, Inc. appealed the termination of its contract for default and related claims for delay. The Board denied both appeals.
Material Facts
- The contract was awarded to DODS, Inc. on January 26, 2011, for the supply of center wing sections for an aerial target system.
- DODS was required to deliver the first article by August 31, 2011.
- The contracting officer issued a cure notice on July 13, 2011, citing DODS' failure to make satisfactory progress.
- DODS' response to the cure notice was deemed inadequate, and it failed to demonstrate the ability to meet the contract requirements.
- The contract was terminated for default on July 27, 2011.
Parties
- Appellant
- DODS, Inc.
- Respondent Agency
- Department of the Army
- Contract Number
- W31P4Q-11-C-0133
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- John C. Grimberg Co., Inc.No. 58791, 59717January 2, 2019
- John C. Grimberg Co., Inc.No. 58791, 59167, 59168, 59169, 59170, 59171, 59717October 25, 2018
- CANVS CorporationNo. 57784, 57987September 6, 2018
- K&K Industries, Inc.No. 61189September 5, 2018
- Northrop Grumman CorporationNo. 60190January 9, 2018
- Nelson, Inc.No. 57201, 58166November 8, 2017
Same Year
- Fluor Enterprises, Inc. and Fluor CorporationNo. 59367, 59697December 24, 2014
- The Boeing CompanyNo. 59216December 24, 2014
- Government Services Corp.No. 59654December 23, 2014
- Raytheon Missile SystemsNo. 59432December 23, 2014
- CAE USA, Inc.No. 58957December 23, 2014
- Metal Storm, Inc.No. 58901December 23, 2014
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- US Military CorpNo. 64321September 24, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Visionary Construction, Inc. dba Visionary ServicesNo. 64426August 20, 2026
- Peritia LLCNo. 64495, 64586August 20, 2026
- J.A.M. Construction Services, Inc.No. 63378, 64226, 64439July 28, 2026