North American Landscaping, Construction and Dredge, Co., Inc.
North American Landscaping, Construction and Dredge, Co., Inc. appealed several claims against the U.S. Army Corps of Engineers regarding a dredging contract, resulting in a mixed outcome.
Material Facts
- NALCO contracted with the U.S. Army Corps of Engineers for maintenance dredging of the Scarborough River.
- NALCO claimed an unpaid contract balance of $960,482.48, unabsorbed overhead of $108,868, differing site conditions of $507,914.19, and a time extension of 94 days.
- The CO invoked DFARS 252.236-7004(b) to limit NALCO's mobilization payments.
- A revetment was constructed by Prouts Neck Country Club, which interfered with NALCO's dredging operations.
Parties
- Appellant
- North American Landscaping, Construction and Dredge, Co., Inc.
- Respondent Agency
- U.S. Army Corps of Engineers
- Contract Number
- W912WJ-14-C-0004
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Metal Trades, Inc.No. 62966November 2, 2021
- Powertronic Systems Florida, Inc.No. 62174October 19, 2021
- Huffman Construction, LLCNo. 62591, 62783August 5, 2021
- U.S. Pan American Solutions, LLCNo. 62629August 5, 2021
- URS Federal Support Services, Inc.No. 59998-QUANAugust 3, 2021
- G&S Carpet Mills, Inc.No. 62799June 25, 2021
Same Year
- AT&T Corp.No. 61868December 21, 2018
- Gilbane Federal Joint VentureNo. 61590December 21, 2018
- WIT Associates, Inc.No. 61547December 19, 2018
- Avis Industries, Inc.No. 61609December 19, 2018
- Tetra Tech Tesoro, Inc.No. 61209, 61210, 61211, 61212 61213, 61214December 19, 2018
- J.F. Brennan Co., Inc.No. 60737December 19, 2018
Same Issue
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- Vigor Marine, LLCNo. 63405September 24, 2026
- US Military CorpNo. 64321September 24, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026