WECC, Inc.

Material Facts

• The contract was awarded to WECC, Inc. on February 13, 2014, for renovations at Langley Air Force Base.
• The contract required WECC to complete the work within 240 days, with liquidated damages of $1,500 per day for delays.
• WECC encountered unexpected conditions that delayed the project, including issues with the concrete slab and a storm drain.
• The government issued several change orders during the project, some of which did not extend the performance period.
• WECC submitted a claim for 249 days of compensable delays and additional costs totaling $1,600,664.26.

Parties

Appellant

WECC, Inc.

Respondent Agency

Army and Air Force Exchange Service

Contract Number

73-0014-1522