Axxon International, LLC
Axxon International, LLC appealed the termination for cause of its contract with the U.S. Army Corps of Engineers for pump repairs, which the Board denied.
Material Facts
- The Corps awarded Axxon a firm fixed-price contract for pump repairs on May 24, 2016.
- The contract included six line items for various equipment and had a delivery date of March 23, 2017.
- Axxon entered into a purchase order with B.H. Craig Construction Company to perform the work for $365,400.
- Axxon submitted multiple invoices for progress payments, but failed to pay Craig as required.
- The Corps issued a show cause notice on August 19, 2017, citing Axxon's delays and noncompliance with payment obligations.
- The Corps terminated Axxon's contract for cause on January 5, 2018, due to inexcusable delays and failure to make required payments.
Parties
- Appellant
- Axxon International, LLC
- Respondent Agency
- U.S. Army Corps of Engineers
- Contract Number
- W912P5-16-C-0002
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- HECO Pacific Manufacturing, Inc.No. 63217, 64512September 1, 2026
- Erik Robinson d/b/a The Artwork FactoryNo. 63727, 63809August 19, 2026
- ACC Construction Co., Inc.No. 63528, 64067July 16, 2026
- Gibraltar-Caddell, a Joint VentureNo. 64379July 13, 2026
- Akima Range Readiness Operations, LLCNo. 64012-ADRJune 4, 2026
- Envistacom, LLCNo. 63796May 13, 2026
Same Year
- Sweet Star Logistic ServiceNo. 62082December 29, 2020
- Nan, Inc.No. 61472, 61482, 61500, 61509, 61514, 61523, 61555, 61569, 61705, 61726, 61727, 61728, 61821, 61822, 61823, 61963December 18, 2020
- Asahi General Trading & Cont. Co. W.L.L.No. 62445December 18, 2020
- Kautaq Construction Services, LLCNo. 62462-ADRDecember 18, 2020
- MAC Electric Inc.No. 62503December 18, 2020
- Parsons Government Services, Inc.No. 62112December 17, 2020
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- US Military CorpNo. 64321September 24, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Visionary Construction, Inc. dba Visionary ServicesNo. 64426August 20, 2026
- Peritia LLCNo. 64495, 64586August 20, 2026
- J.A.M. Construction Services, Inc.No. 63378, 64226, 64439July 28, 2026