Sungjee Construction Co., Ltd.

Material Facts

• On August 14, 2014, the 411 CSB awarded Sungjee indefinite-delivery, indefinite-quantity (IDIQ) Contract No. W91QVN-14-D-0050.
• The Army terminated the task order for default due to appellant’s failure to complete the project by the contract completion date (CCD).
• The task order included instructions regarding access to the base, stating that contractor employees must provide information for background checks.
• Sungjee submitted its preliminary and initial project schedule on August 12, 2016, which was government-approved.
• Sungjee requested a 90-day extension two months before the CCD, citing cold weather and additional work.
• The government issued a no-cost unilateral Modification No. 02 on September 21, 2017, extending the CCD to December 23, 2017.
• Sungjee continued to request extensions and admitted fault for delays due to financial problems.
• On July 19, 2018, the COR informed Sungjee it would terminate the order for default for failure to complete the project.

Parties

Appellant

Sungjee Construction Co., Ltd.

Respondent Agency

Department of the Army

Contract Number

W91QVN-14-D-0050