Konecranes Nuclear Equipment & Services, LLC
Konecranes Nuclear Equipment & Services, LLC appealed the Navy's contracting officer's final decisions denying its claims for contract interpretation and delay damages. The Board sustained Konecranes' appeals and awarded damages.
Material Facts
- The Navy awarded Konecranes contract No. N62470-16-D-2013 to design, fabricate, assemble, and deliver four portal cranes.
- The Navy refused to accept delivery of the cranes after an initial test revealed damage to the luffing drum.
- Konecranes identified and fixed the problem with the luffing drum but the Navy demanded an unnecessary alternative solution.
- The Board conducted a six-day hearing on entitlement and quantum.
- Konecranes' cranes were found to meet contractual requirements and were ready for delivery.
Parties
- Appellant
- Konecranes Nuclear Equipment & Services, LLC
- Respondent Agency
- Department of the Navy
- Contract Number
- N62470-16-D-2013
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Cardinal Contracting Co., LLCNo. 62872July 30, 2026
- PDO Ahusaka Joint Venture LLCNo. 64490July 23, 2026
- Al Ghanim Combined Group W.L.L.No. 62321, 62984May 18, 2026
- EFS Ebrex SarlNo. 64073-ADR, 64074-ADR, 64075-ADR, 64194-ADR, 64195-ADR, 64196-ADR, 64197-ADRApril 30, 2026
- Endure Industries, Inc.No. 64064March 23, 2026
- Sheffield Barbers, LLCNo. 62367February 26, 2026
Same Year
- Red Bobtail TransportNo. FY24-03December 19, 2024
- Pacific Scientific Energetic Materials CompanyNo. 63739-ADRDecember 19, 2024
- Sauer IncorporatedNo. 62302, 62303December 18, 2024
- A Best Services Inc.No. 63816December 12, 2024
- Asturian Group, Inc.No. 63687December 10, 2024
- US21, Inc.No. 63830December 10, 2024
Same Issue
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026
- DCS CorporationNo. 64648September 22, 2026
- VAE, Inc.No. 64437, 64464, 64465September 9, 2026
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026