Al Ghanim Combined Group W.L.L.
Al Ghanim Combined Group W.L.L. appealed for delay costs from the United States Army Corps of Engineers due to delays in obtaining security escorts for construction work in Kuwait. The Board sustained the appeal, awarding Al Ghanim $34,320.11 plus interest.
Material Facts
- The Army Corps awarded Al Ghanim an indefinite delivery/indefinite quantity job order contract on November 7, 2013.
- Al Ghanim was tasked with construction work at Camp Ali Al Salem, Kuwait, requiring security escorts as per Air Force regulations.
- Delays occurred due to the late arrival of security escorts, impacting Al Ghanim's ability to commence work on time.
- Al Ghanim submitted requests for equitable adjustment seeking time extensions and costs for delays from January to October 2018.
- The contracting officer recognized some delays but denied any cost adjustments, stating they were non-compensable.
Parties
- Appellant
- Al Ghanim Combined Group W.L.L.
- Respondent Agency
- United States Army Corps of Engineers
- Contract Number
- W912ER-14-D-0005
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Cardinal Contracting Co., LLCNo. 62872July 30, 2026
- PDO Ahusaka Joint Venture LLCNo. 64490July 23, 2026
- EFS Ebrex SarlNo. 64073-ADR, 64074-ADR, 64075-ADR, 64194-ADR, 64195-ADR, 64196-ADR, 64197-ADRApril 30, 2026
- Endure Industries, Inc.No. 64064March 23, 2026
- Sheffield Barbers, LLCNo. 62367February 26, 2026
- Kawasaki Rail Car, Inc.No. 63884-ADRFebruary 10, 2026
Same Year
- Bodell Construction CompanyNo. 63517-ADR, 63850-ADROctober 2, 2026
- Procal Electric, Inc.No. 63580-ADROctober 2, 2026
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Kearfott CorporationNo. 64328October 1, 2026
- Relyant Global, LLCNo. 64606October 1, 2026
- Relyant Global, LLCNo. 64651October 1, 2026
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026
- Hensel Phelps Construction CompanyNo. 64327September 14, 2026
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Marine Hydraulics International, LLCNo. 63429, 63511August 6, 2026