Kolin Construction, Tourism, Industry and Trading Co., Inc.
Kolin Construction, Tourism, Industry and Trading Co., Inc. appealed two decisions regarding delays in a contract for housing renovations at Incirlik Air Base, Turkey. The Board denied the government's motions for judgment on the pleadings and for summary judgment.
Material Facts
- Kolin Construction was awarded Contract No. FA5685-06-C-0029 for the renovation of housing units at Incirlik Air Base.
- The contract included provisions requiring Turkish General Staff approval for material lists.
- Kolin submitted a material list that was approved by the Turkish government but was directed by the U.S. government to procure certain imported items.
- The Turkish Air Force subsequently imposed restrictions on the use of imported materials, causing delays in construction.
- Kolin submitted claims for delays and disruption costs, which were denied by the contracting officer.
Parties
- Appellant
- Kolin Construction, Tourism, Industry and Trading Co., Inc.
- Respondent Agency
- Department of the Air Force
- Contract Number
- Contract No. FA5685-06-C-0029
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Kellogg Brown & Root Services, Inc.No. 59357, 59358August 29, 2016
- GSC Construction, Inc.No. 59644, 59956, 60069, 60070, 60112, 60113June 21, 2016
- Access Personnel Services, Inc.No. 59900June 15, 2016
- CI², Inc.No. 59948June 6, 2016
- CI², Inc.No. 59948June 6, 2016
- CI², Inc.No. 59948June 6, 2016
Same Year
- Joint Venture Makyal Ins. Ve Tic. A.S. & Mehmet Erdal Kamisli Co. Ltd.No. 56956December 28, 2011
- Distributed Solutions, Inc.No. 57266December 28, 2011
- Quimba Software, Inc.No. 57636December 19, 2011
- American General Trading & Contracting, WLLNo. 56758December 13, 2011
- Harry RichardsonNo. 57582December 9, 2011
- Sharp Electronics CorporationNo. 57583December 6, 2011
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026
- Hensel Phelps Construction CompanyNo. 64327September 14, 2026
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Marine Hydraulics International, LLCNo. 63429, 63511August 6, 2026