American International Contractors, Inc.
American International Contractors, Inc. (AICI) sought reconsideration of a prior ASBCA decision that denied its motion for summary judgment and partially granted the government's cross-motion. The Board denied the motion for reconsideration.
Material Facts
- AICI moved for reconsideration of the Board's prior decision.
- Modification No. POOO 11 added 232 days and $168,710 to perform four discrete items of work.
- AICI contended that the government should return $159,055 in withheld liquidated damages.
- It was undisputed that the modification's value and term came directly from AICI's proposal.
- AICI refused to sign the modification, seeking an unspecified additional amount for oversight of the work.
Parties
- Appellant
- American International Contractors, Inc.
- Respondent Agency
- U.S. Army Engineer District, Middle East
- Contract Number
- W912ER-14-C-0002
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Korte Construction CompanyNo. 63539, 63540September 30, 2026
- Dubai Pearl CompanyNo. 64444August 26, 2026
- U.S. Aeroteam, Inc.No. 61972, 61973August 6, 2026
- J. Star Enterprises, Inc.No. 63627, 63647, 63656, 63657, 63658June 10, 2026
- J. Star Enterprises, Inc.No. 63603June 9, 2026
- Vectrus Systems CorporationNo. 63420May 11, 2026
Same Year
- AT&T Corp.No. 61868December 21, 2018
- Gilbane Federal Joint VentureNo. 61590December 21, 2018
- WIT Associates, Inc.No. 61547December 19, 2018
- Avis Industries, Inc.No. 61609December 19, 2018
- Tetra Tech Tesoro, Inc.No. 61209, 61210, 61211, 61212 61213, 61214December 19, 2018
- J.F. Brennan Co., Inc.No. 60737December 19, 2018
Same Issue
- Africa Transport Logistics CompanyNo. 64120October 1, 2026
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Martin Brothers ConstructionNo. 63196, 63431September 30, 2026
- Vigor Marine, LLCNo. 63405September 24, 2026
- US Military CorpNo. 64321September 24, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026