PricingGAO ProtestASBCACMMCMCPFAQResources
6102061021610616114661278

Cutter Enterprises, LLC

February 17, 2026Judge Osterhout
Denied / Government PrevailedTermination for Default

Cutter Enterprises, LLC appealed the termination for default of a $31.5 million construction contract with the New Hampshire Air National Guard, which the Board denied.

Material Facts

  • The contract was a $31.5 million construction contract between Cutter Enterprises, LLC and the New Hampshire Air National Guard.
  • The contract involved altering two existing KC-135R aircraft hangar buildings at Pease Air National Guard Base.
  • The government terminated the contract for default after a series of delays and issues.
  • Cutter filed five appeals regarding the termination and claims for time extensions and costs.

Parties

Appellant
Cutter Enterprises, LLC
Respondent Agency
New Hampshire Air National Guard
Contract Number
Contract No. W912TF-15-C-0500
Open Official Decision PDF (asbca.mil)AI-analyzed, grounded in the decision text. Verify against the official PDF before relying on it.

Full Legal Analysis

Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.

Holding & Legal Reasoning

The Board's holding, background, and procedural posture for this decision.

View plans and pricing

Issues Presented

Every issue the Board decided, with its determination, reasoning, and supporting authority.

View plans and pricing

Quantum & Recovery

The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.

View plans and pricing

Verified Authorities & Citations

Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.

View plans and pricing

Practitioner Takeaways

Practical guidance for contractors and counsel, distilled from the Board's ruling.

View plans and pricing

Similar Cases

Related decisions surfaced by semantic search across the full analyzed corpus.

View plans and pricing

Citation Graph

An interactive graph of this case's cited authorities, judge, agency, and related decisions.

View plans and pricing

Related Decisions

Same Judge

Same Year

Same Issue

Newsletter

New decisions every Monday

GovConDash Weekly lists the decisions GAO, the boards, the courts and SBA OHA released that week, alongside the FAR Overhaul deviations and proposed rules that reach every contractor. Free.

Free, weekly, and one click to unsubscribe. We send a confirmation email first. See our Privacy Policy.