PricingGAO ProtestASBCACMMCMCPFAQResources
62119

KiewitPhelps

May 4, 2026Judge Eyester
Partially SustainedDelay / Disruption / SuspensionDCAA Involved

KiewitPhelps appealed a decision regarding claims for delays and disruptions in the construction of a command facility for the U.S. Strategic Command, resulting in a finding of entitlement for certain costs associated with the delays.

Material Facts

  • The contract was a fixed-price construction contract awarded to KP for the construction of a command facility.
  • The project was located at Offutt Air Force Base, Nebraska.
  • KP filed multiple claims related to the construction, including the current appeal for delays from November 30, 2014, to April 19, 2018.
  • The Corps acknowledged that KP was entitled to 'something' but disputed the specifics of the claims.
  • The Board found that the Corps' actions caused disruptions and inefficiencies impacting KP and its subcontractors.

Parties

Appellant
KiewitPhelps
Respondent Agency
U.S. Army Corps of Engineers
Contract Number
W9128F-12-C-0023
Open Official Decision PDF (asbca.mil)AI-analyzed, grounded in the decision text. Verify against the official PDF before relying on it.

Full Legal Analysis

Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.

Holding & Legal Reasoning

The Board's holding, background, and procedural posture for this decision.

View plans and pricing

Issues Presented

Every issue the Board decided, with its determination, reasoning, and supporting authority.

View plans and pricing

Quantum & Recovery

The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.

View plans and pricing

Verified Authorities & Citations

Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.

View plans and pricing

Practitioner Takeaways

Practical guidance for contractors and counsel, distilled from the Board's ruling.

View plans and pricing

Similar Cases

Related decisions surfaced by semantic search across the full analyzed corpus.

View plans and pricing

Citation Graph

An interactive graph of this case's cited authorities, judge, agency, and related decisions.

View plans and pricing

Related Decisions

Same Judge

Same Year

Same Issue

Newsletter

New decisions every Monday

GovConDash Weekly lists the decisions GAO, the boards, the courts and SBA OHA released that week, alongside the FAR Overhaul deviations and proposed rules that reach every contractor. Free.

Free, weekly, and one click to unsubscribe. We send a confirmation email first. See our Privacy Policy.