Wright Brothers, the Building Company, Eagle LLC

Material Facts

• The government awarded Wright Brothers Contract No. FA4528-14-C-3001 for the repair and renovation of Building 1113WSA.
• The original contract period was 365 days, with multiple modifications extending the completion date by a total of 659 days.
• As of September 3, 2017, the project was not complete, and liquidated damages were assessed starting November 6, 2017.
• Wright Brothers submitted a claim for $753,816.77, which included a request for equitable adjustment due to government-caused delays.
• The contracting officer's final decision noted that the government accepted responsibility for 583 days of delay.

Parties

Appellant

Wright Brothers, the Building Company, Eagle LLC

Contract Number

FA4528-14-C-3001