RLB Contracting, Inc.
RLB Contracting, Inc. appealed the denial of its claim for a time extension and remission of liquidated damages after striking a submerged pipeline during dredging work for the U.S. Army Corps of Engineers. The Board granted the government's motion for summary judgment, dismissing the appeal.
Material Facts
- RLB performed dredging work for the U.S. Army Corps of Engineers.
- RLB struck a submerged natural gas pipeline, causing an explosion and damage to the dredger.
- The Corps imposed liquidated damages on RLB for delays in contract completion.
- RLB submitted a claim for a time extension and remission of liquidated damages, which was denied by the contracting officer.
- RLB's appeal was based on claims of defective specifications, differing site conditions, and breach of good faith.
Parties
- Appellant
- RLB Contracting, Inc.
- Respondent Agency
- U.S. Army Corps of Engineers
- Contract Number
- Contract No. W9126G-17-C-0043
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Procal Electric, Inc.No. 63580-ADROctober 2, 2026
- VESEQU LLCNo. 64468August 21, 2026
- PDO Ahuska Joint Venture LLCNo. 64164July 13, 2026
- First Street Contractors, LLCNo. 64028June 10, 2026
- VESEQU LLCNo. 64468May 21, 2026
- First Street Contractors, LLCNo. 64028February 20, 2026
Same Year
- Central Environmental, Inc.No. 62628December 28, 2023
- Horizon Environmental Services, Inc.No. 63428, 63463December 28, 2023
- O-Tech Solutions, LLCNo. 61898-EAJA, 62095-EAJADecember 26, 2023
- PAE Applied Technologies LLCNo. 63233December 26, 2023
- G-W Management Services, LLCNo. 63318December 26, 2023
- SOC LLCNo. 63660December 22, 2023
Same Issue
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026
- Hensel Phelps Construction CompanyNo. 64327September 14, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Warrior Construction Services, Inc.No. 64497August 7, 2026
- U.S. Aeroteam, Inc.No. 61972, 61973August 6, 2026
- Bahadir Construction Engineering Contracting & Trading Inc. Co. and Impreza Costruzioni Giuseppe Maltauro S.p.A Joint VentureNo. 64038, 64336, 64428July 16, 2026