Troy Eagle Group
Troy Eagle Group appealed a decision regarding delay and material restocking costs under a contract for vehicle upgrades for the Iraqi National Police. The Board partially granted the government's motion for summary judgment, denying some claims while allowing others to proceed.
Material Facts
- TEG was awarded a contract for up-armoring and upgrading vehicles for the Iraqi National Police.
- The total fixed-price amount of the contract was $5,798,180 with a performance period of 240 days.
- TEG encountered design problems and received a Stop Work Order from the contracting officer.
- Modifications to the contract increased the price and extended the performance period.
- TEG delivered 175 vehicles by November 2007 but faced delays due to various issues, including security and the Iraqi police's schedule.
- TEG submitted a request for an equitable adjustment of $6,475,720, which included claims for material restocking and extended overhead.
Parties
- Appellant
- Troy Eagle Group
- Respondent Agency
- Department of the Army
- Contract Number
- W91GY0-07-C-0008
Full Legal Analysis
Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.
Holding & Legal Reasoning
The Board's holding, background, and procedural posture for this decision.
Issues Presented
Every issue the Board decided, with its determination, reasoning, and supporting authority.
Quantum & Recovery
The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.
Verified Authorities & Citations
Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.
Practitioner Takeaways
Practical guidance for contractors and counsel, distilled from the Board's ruling.
Similar Cases
Related decisions surfaced by semantic search across the full analyzed corpus.
Citation Graph
An interactive graph of this case's cited authorities, judge, agency, and related decisions.
Related Decisions
Same Judge
- Applied Technical Systems, Inc.No. 58072March 6, 2014
- Bulova Technologies Ordnance Systems LLCNo. 57406January 28, 2014
- Stephens Construction and Concrete, Inc.No. 58670January 2, 2014
- New Iraq Ahd CompanyNo. 58800December 17, 2013
- Dace Enterprises, LLCNo. 57984November 1, 2013
- Kellogg Brown & Root Services, Inc.No. 58578September 9, 2013
Same Year
- WorleyParsons International, Inc.No. 57930December 20, 2013
- TTF, L.L.C.No. 58452December 19, 2013
- Bruce E. ZoellerNo. 56578December 17, 2013
- New Iraq Ahd CompanyNo. 58800December 17, 2013
- Linc Government Services, LLCNo. 58561, 58562, 58563, 58565, 58566, 58567December 5, 2013
- Fluor CorporationNo. 57852December 5, 2013
Same Issue
- Huffman Construction, LLCNo. 62591, 62783September 30, 2026
- Scot Cardillo dba Engineers Tooling SupportNo. 61612September 22, 2026
- Hensel Phelps Construction CompanyNo. 64327September 14, 2026
- Hensel Phelps Construction Co.No. 63316, 63397, 63398August 28, 2026
- Relyant Global LLCNo. 64032, 64111, 64230, 64231, 64517August 24, 2026
- Marine Hydraulics International, LLCNo. 63429, 63511August 6, 2026