PricingGAO ProtestASBCACMMCMCPFAQResources
62967

DTH Corporation

June 9, 2025Judge Woodrow
Partially SustainedDelay / Disruption / SuspensionContract Changes / Constructive ChangesQuantum / DamagesAccord & Satisfaction / Release / Waiver

DTH Corporation appealed a decision regarding a contract dispute with the Air Force over additional compensation for alleged changes and delays in a construction project. The Board awarded DTH $70,778.14 for a delay but denied all other claims.

Material Facts

  • DTH Corporation entered into a contract with the Air Force to construct a helicopter storage area at Moody Air Force Base.
  • DTH submitted a claim for additional compensation related to various alleged changes and delays totaling over $2.7 million.
  • The Air Force issued Delivery Order No. 2003 under the MACC to DTH for $6,586,540.
  • The contract stipulated a 90-day design and 360-day construction period.
  • DTH was awarded $70,778.14 for an 89-day delay attributable to the Air Force.

Parties

Appellant
DTH Corporation
Respondent Agency
Air Force
Contract Number
FA4830-14-D-0006
Open Official Decision PDF (asbca.mil)AI-analyzed, grounded in the decision text. Verify against the official PDF before relying on it.

Full Legal Analysis

Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.

Holding & Legal Reasoning

The Board's holding, background, and procedural posture for this decision.

View plans and pricing

Issues Presented

Every issue the Board decided, with its determination, reasoning, and supporting authority.

View plans and pricing

Quantum & Recovery

The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.

View plans and pricing

Verified Authorities & Citations

Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.

View plans and pricing

Practitioner Takeaways

Practical guidance for contractors and counsel, distilled from the Board's ruling.

View plans and pricing

Similar Cases

Related decisions surfaced by semantic search across the full analyzed corpus.

View plans and pricing

Citation Graph

An interactive graph of this case's cited authorities, judge, agency, and related decisions.

View plans and pricing

Related Decisions

Same Judge

Same Year

Same Issue

Newsletter

New decisions every Monday

GovConDash Weekly lists the decisions GAO, the boards, the courts and SBA OHA released that week, alongside the FAR Overhaul deviations and proposed rules that reach every contractor. Free.

Free, weekly, and one click to unsubscribe. We send a confirmation email first. See our Privacy Policy.