PricingGAO ProtestASBCACMMCMCPFAQResources
63006

West Point Utilities, LLC

September 4, 2025Judge Woodrow
Partially SustainedTermination for DefaultCDA Jurisdiction

West Point Utilities, LLC appealed a default termination under an IDIQ contract for construction projects, challenging the termination and seeking damages. The Board found it lacked jurisdiction over certain claims but denied the government's motion for summary judgment on the default termination.

Material Facts

  • West Point Utilities, LLC was awarded a $249 million IDIQ MACC for construction projects.
  • The dispute centers on Task Order No. N62473-20-F-4216 for water treatment plant repairs.
  • The original completion date was September 22, 2021, later extended to May 12, 2022.
  • The contracting officer terminated West Point for default due to performance delays.
  • West Point challenged the termination and sought conversion to a termination for convenience.

Parties

Appellant
West Point Utilities, LLC
Respondent Agency
Navy
Contract Number
Contract No. N62473-19-D-1206
Open Official Decision PDF (asbca.mil)AI-analyzed, grounded in the decision text. Verify against the official PDF before relying on it.

Full Legal Analysis

Create a free account to read the complete grounded legal brief for this decision, including the holding, every issue the Board decided, quantum, verified citations, and the case's citation graph.

Holding & Legal Reasoning

The Board's holding, background, and procedural posture for this decision.

View plans and pricing

Issues Presented

Every issue the Board decided, with its determination, reasoning, and supporting authority.

View plans and pricing

Quantum & Recovery

The claimed, awarded, and net dollar amounts at issue, itemized where the record supports it.

View plans and pricing

Verified Authorities & Citations

Every cited FAR, DFARS, CAS, and case-law authority, cross-checked against the source text.

View plans and pricing

Practitioner Takeaways

Practical guidance for contractors and counsel, distilled from the Board's ruling.

View plans and pricing

Similar Cases

Related decisions surfaced by semantic search across the full analyzed corpus.

View plans and pricing

Citation Graph

An interactive graph of this case's cited authorities, judge, agency, and related decisions.

View plans and pricing

Related Decisions

Same Judge

Same Year

Same Issue

Newsletter

New decisions every Monday

GovConDash Weekly lists the decisions GAO, the boards, the courts and SBA OHA released that week, alongside the FAR Overhaul deviations and proposed rules that reach every contractor. Free.

Free, weekly, and one click to unsubscribe. We send a confirmation email first. See our Privacy Policy.